Quote from WNH Construction Inc. - 01/03/2024

["WNH Construction Inc." <http://www.getjobber.com/~notification>]

Logo  
WNH Construction Inc.

Estimate

Hi Robert, Thank you for asking us to quote on your project. Please find a detailed copy of our quote attached to this email. The quote total is $880.00 as of 01/03/2024. If you have any questions or concerns regarding this quote, please don't hesitate to get in touch with us at http://www.earthquakeretrofit.com/~info. Sincerely, WNH Construction Inc.

Details
  View Estimate //

Total $880.00

Required deposit $88.00

Button not working? Copy and paste this link to your browser address bar: https://clienthub.getjobber.com/client_hubs/f982b818-5f50-4a42-8b79-0311bdc09576/quotes/29276193.html?auth_token=eyJhbGciOiJIUzI1NiJ9.eyJidW5rZXJfdXNlcl9pZCI6NzU5MjE4ODgsImRlbGVnYXRlIjpmYWxzZSwiZXhwIjoxNzA1NTM4NjIxfQ.kJcTX050746FjCSLeO_obu5pwpNfOCd2LCxzP2bxax8&comm_channel=email&comm_type=quote_sent&utm_content=in_email_cta&utm_medium=email&utm_source=sendgrid

WNH Construction Inc. 510-648-9999 http://www.earthquakeretrofit.com/~info 20018 Knollwood Dr Saratoga CA 95070 CSLB# 1031584

Powered by Jobber ,https://url6691.getjobber.com/ls/click?upn=Gx6Pf38gonqBsndfmYW-2Bgfb5dGCOgNQ0M25j2oAOJITaXthjiv7cBiq8aqx-2B6ILoi3OcWPTQl-2BdKT-2B1Nwv-2Fucj7M5lBN3pDi1EX-2FagKpsr8cOVUQU6MDcpqSDkg3KwU3lP6U8ztmFbgiLveDKE1OZw-3D-3DOgR__KWg3QX2t9dBAgSfjCKLYmJIqfyw3NsVbEqFlOwd-2Fmu3mCOFUmSiUaiRBmy1t75RtDfZiQZYiadALYfpA9Rn55c-2BJJPBBPv15b2-2BGmlen7ueg96i-2F8Fg9SX4DM3NquE8Y3YWlMCHJp-2B8UY9klpa-2FLig60c2bB7p4RraEFODwd0TUfbBHzCnhnW25vDJ0883PXK8ARaVzkRe5VN8juYeCKBdspncuKr6R030IZaBn4fzP4eV17o-2FtkTxL1Lep9JbRBQs9e-2Fsxg8l0kv2V3vW62cBsu-2F-2F3LzcEWMt2qJE7WVwETy-2FzYApaOwyMXpJ6vzr7aesG9WbPvIWLVzHDPIUKpdsWnVqAw0BwSyg-2FwW-2FXOuVrtpd6R8MjLmvDlxW8ckgJj, Copyright � 2024, Octopusapp, Inc.  
     

Content-Type: application/pdf;  filename=estimate_4125.pdf
Content-Transfer-Encoding: base64
Content-Disposition: attachment;  filename=estimate_4125.pdf

WNH Construction Inc.
20018 Knollwood Dr | Saratoga CA 95070 | CSLB# 1031584
510-648-9999 | http://www.earthquakeretrofit.com/~info | WNHconstruction.com

RECIPIENT:

Estimate #4125

Robert

Sent on

 
where-I-live 
Phone: my-Oakland-voicemail-number

01/03/2024

Total

Product/Service

Description

AC6 Pier Caps

We will install Simpson's AC6 pier caps for all your
piers in the crawl space.
Post caps connect tops of posts to members for a
secure connection and are ideal for new or retrofit
applications where structural support is needed.
Post caps are available in a variety of one-piece
caps for new construction and two-piece options
for retrofit of existing connections. The AC series is
designed to provide a positive connection between
a beam and a post; these connectors are always
installed in pairs

$880.00
Qty.

Unit Price

Total

22

$40.00

$880.00

A deposit of $88.00 will be required to begin.

Total

$880.00

Insured / licensed Information
Working is dangerous. Did you know that if anyone gets hurt working on your
property? You can be potentially liable? *It is important to protect your self 
from
lawsuits* by hiring companies that carry Liability Insurance and Worker's
Compensation. Ask them if they carry worker's compensation. WNH is licensed,
we carry a 1 million dollar commercial liability insurance and Worker's
Compensation to protect you and our workers.

Terms and Conditions

1 of 6 pages

WNH Construction Inc.
20018 Knollwood Dr | Saratoga CA 95070 | CSLB# 1031584
510-648-9999 | http://www.earthquakeretrofit.com/~info | WNHconstruction.com

Notes Continued...
CONSTRUCTION CONTRACT
(Home Improvement)
Complies with Section 7159 of Ca Business and Professional Code, and 
Civil Code Section 3097 (1) as amended.
THIS AGREEMENT IS MADE AS OF THE INVOICE DATE BETWEEN WNH Construction Inc. and 
Parties listed on the Quote:
(RECIPIENT:). The project location shall be the RECIPIENT: service address.
CONTRACT PRICE: Owner shall pay Contractor the fixed sum of Total Quoted Price (
the “TOTAL”) for the work to be performed under
this Contract, subject to additions, deductions, and any agreed on fees, 
pursuant to change orders agreed upon in writing by the parties.
DOWN PAYMENT: 10%
THE DOWN PAYMENT MAY NOT EXCEED $1,000 OR 10% OF THE CONTRACT PRICE, WHICHEVER 
IS LESS.
START AND COMPLETION OF WORK: The work to be performed under this Contract 
shall be commenced on approximately "SEE
NOTES" if nothing is listed then within 5 months of the signed contract" as 
long as any required building permits are received and any
agreed upon funds are paid to Contractor. The Project shall be completed by 
approximately "See Notes", If nothing is listed, then 60 Days
from scheduled start date. Subject to permissible delays as defined in this 
contract.
HIDDEN CONDITIONS CLAUSE.
The client bears responsibility should underground or otherwise hidden 
conditions be encountered or later discovered which are not shown
on plans, or are contrary to those conditions represented on plans, or are such 
as a reasonably diligent contractor would not have foreseen.
Work arising from such hidden conditions may be the subject of a Change Order 
and WNH bears no responsibility for this work. The
following is a non-exhaustive list of examples: existing footings deeper than 
represented on plans; archaeological matters; unmarked utility
lines in the path of excavations; buried waste, water lines, electrical lines, 
dry-rot.
WNH is not responsible for substandard electrical wire, network wires, 
telephone wire, or low-voltage wiring inside areas of walls where
improvements will be installed.
SCHEDULE OF PROGRESS PAYMENTS:
Deposit 10 %of project price or $1000 whichever is less.
Then Progress payment listed under "General Notes" if no payment schedule is 
listed. The default will be 10% percent deposit. Then
balance is due when work has been completed.
You have 7 Business days to make the final payment. If payment is not received 
after the 7th business day. We reserve the right to assess
a $50.00 late fee. Then 1.5% percent for any unpaid balances.
Deposit can be paid by Check and Credit Card. All other payments will be made 
by check, credit card or cash.
IT IS AGAINST THE LAW FOR A CONTRACTOR TO COLLECT PAYMENT FOR WORK NOT YET 
COMPLETED, OR FOR
MATERIALS NOT YET DELIVERED. HOWEVER, A CONTRACTOR MAY REQUIRE A DOWN PAYMENT
Upon satisfactory payment being made for any portion of the work performed the 
contractor shall, prior to any further payment being made,
furnish to the person contracting for the home Improvement or swimming pool 
work a full and unconditional release from any claim or
mechanic’s lien pursuant to Section 3114 of the Civil Code for that portion 
of the work for which payment has been made.
(If necessary, continue the description of the work on an additional attachment 
page and describe the attachment in the section below
entitled “List of Documents to be incorporated into the Contract.”)
CONSUMER NOTICES
LIST OF DOCUMENTS TO BE INCORPORATED INTO THE CONTRACT:
Additional Consumer Notices:
• Commercial General Liability Insurance
• Workers’ Compensation Insurance
• Performance of Extra or Change-order Work Notice
• Mechanics’ Lien Warning
• Contractors Board Notice
• Notice of Cancellation
• Arbitration of Disputes

2 of 6 pages

WNH Construction Inc.
20018 Knollwood Dr | Saratoga CA 95070 | CSLB# 1031584
510-648-9999 | http://www.earthquakeretrofit.com/~info | WNHconstruction.com

Notes Continued...
• Three/Seven-Day Right to Cancel
• (List any additional attachments):_____________________________________
COMMERCIAL GENERAL LIABILITY INSURANCE (CGL)
This contractor carries commercial general liability insurance
WORKERS’ COMPENSATION INSURANCE
This contractor carries workers’ compensation insurance for all employees.
PERMISSIBLE DELAYS
Identifies potential delays that are acceptable
The Contractor is not responsible for delays due to any of the following 
reasons: failure of issuance of all necessary permits, failure to
provide Custom Materials, act of omission by the Owners or the Owners' agent, 
stormy or inclement weather. (Issues arising from The City
officials not the contractors fault.) Change Orders that will increase 
construction time. Items not on approved plans.
ATTORNEY FEES- Each Party shall be responsible for their own expense.
NOTIFICATIONS AND DISCLOSURE STATEMENTS
Note about Extra Work and Change Orders:
Extra Work and Change Orders become part of the contract once the order is 
prepared in writing and signed by the parties prior to the
commencement of any work covered by the new change order. The order must 
describe the scope of the extra work or change, the cost to
be added or subtracted from the contract, and the effect the order will have on 
the schedule of progress payments. The owner may not
require a contractor to perform extra or change-order work without providing 
written authorization prior to the commencement of any work
covered by the new change order. Extra work or a change order is not 
enforceable against an owner unless the change order also identifies
all of the following in writing prior to the commencement of any work covered 
by the new changer order:
(i) The scope of work encompassed by the order; (ii) The amount to be added or 
subtracted from the contract; and (iii) The effect the order
will make in the progress payments or the completion date. The contractor’s 
failure to comply with the requirements of this paragraph does
not preclude the recovery of compensation for work performed based upon legal 
or equitable remedies designed to prevent unjust
enrichment.
Changes in the Work:
Should the Owner, construction lender, or any public body or inspector direct 
any modification or addition to the work covered by this
contract, the contract price shall be adjusted accordingly.
Modification or addition to the work shall be executed only when a Contract 
Change Order has been signed by both the Owner and the
Contractor. The change in the Contract Price caused by such Contract Change 
Order shall be as agreed to in writing, or if the parties are
not in agreement as to the change in Contract Price, the Contractor’s actual 
cost of all labor, equipment, subcontracts and materials, plus a
Contractor’s fee of 15% shall be the change in Contract Price. The Contract 
Change Order may also increase the time within which the
contract is to be completed.
Contractor shall promptly notify the Owner of (a) subsurface or latent physical 
conditions at the site differing materially from those indicated
in the contract, or (b) unknown physical conditions differing materially from 
those ordinarily encountered and generally recognized as
inherent in work of the character provided for in this contract. Any expense 
incurred due to such conditions shall be paid for by the Owner
as added work.
MECHANIC’S LIEN WARNING
Anyone who helps improve your property, but who is not paid, may record what is 
called a mechanic’s lien on your property. A mechanic’s
lien is a claim, like a mortgage or home equity loan, made against your 
property and recorded with the county recorder.
Even if you pay your contractor in full, unpaid subcontractors, suppliers and 
laborers who helped to improve your property may record
mechanics’ liens and sue you in court to foreclose the lien. If a court finds 
the lien is valid, you could be forced to pay twice or have a court
officer sell your home to pay the lien. Liens can also affect your credit.
To preserve their right to record a lien, each subcontractor and material 
supplier must provide you with a document called a “20-day
Preliminary Notice.” This notice is not a lien. The purpose of the notice is 
to let you know that the person who sends you the notice has the
right to record a lien on your property if he or she is not paid.
BE CAREFUL. The Preliminary Notice can be sent up to 20 days after the 
subcontractor starts work or the supplier provides material. This
can be a big problem if you pay your contractor before you have received the 
Preliminary Notices.
You will not get Preliminary Notices from your prime contractor or from 
laborers who work on your project. The law assumes that you
already know they are improving your property.

3 of 6 pages

WNH Construction Inc.
20018 Knollwood Dr | Saratoga CA 95070 | CSLB# 1031584
510-648-9999 | http://www.earthquakeretrofit.com/~info | WNHconstruction.com

Notes Continued...
PROTECT YOURSELF FROM LIENS. You can protect yourself from liens by getting a 
list from your contractor of all the subcontractors
and material suppliers that work on your project. Find out from your contractor 
when these subcontractors started work and when these
suppliers delivered goods or materials. Then wait 20 days, paying attention to 
the Preliminary Notices you receive.
PAY WITH JOINT CHECKS. One way to protect yourself is to pay with a joint 
check. When your contractor tells you it is time to pay
for the work of a subcontractor or supplier who has provided you with a 
Preliminary Notice, write a joint check payable to both the
contractor and the subcontractor or material supplier.
For other ways to prevent liens, visit CSLB’ web site at www.cslb.ca.gov or 
call CSLB at 800-321-CSLB (2752)
REMEMBER, IF YOU DO NOTHING, YOU RISK HAVING A LIEN PLACED ON YOUR HOME. This 
can mean that you may have to pay
twice, or face the forced sale of your home and pay what you owe.
Information about the Contractor’s State License Board (CSLB): CSLB is the 
state consumer protection agency that licenses and regulates
construction contractors. Contact CSLB for information about the licensed 
contractor you are considering, including information about
disclosable complaints, disciplinary actions and civil judgments that are 
reported to CSLB. Use only licensed contractors. If you fi le a
complaint against a licensed contractor within the legal deadline (usually four 
years), CSLB has authority to investigate the complaint. If you
use an unlicensed contractor, CSLB may not be able to help you resolve your 
complaint. Your only remedy may be in civil court, and you
may be liable for damages arising out of any injuries to the unlicensed 
contractor or the unlicensed contractor’s employees.
For more information:
Visit CSLB’s web site at www.cslb.ca.gov
Call CSLB at 800-321-CSLB (2752)
Write CSLB at box 6000, Sacramento, CA 95826
PRINT AND MAIL
NOTICE OF CANCELLATION
Date: ________________________
You have the right to cancel this transaction within three business days of the 
above contract date (or seven days- only for repair or
restoration of a residential premise damaged by a disaster upon which a state 
of emergency has been declared).
If you cancel, any property traded in, any payments made by you under the 
contract or sale, and any negotiable instrument executed by you
will be returned within 10 days following receipt by the seller of your 
cancellation notice and any security interest arising out of the
transaction will be cancelled.
If you cancel, you must make available to the seller at your residence in 
substantially as good condition as when received, any goods
delivered to you under this contract or sale, or you may, if you wish, comply 
with the instruction of the seller regarding the return shipment of
the goods at the seller’s expense and risk.
If you do make the goods available to the seller and the seller does not pick 
them up within 20 days of the date of your notice of
cancellation, you may retain or dispose of the goods without any further 
obligation.
If you fail to make the goods available to the seller, or if you agree to 
return the goods to the seller and fail to do so, then you remain liable
for the performance of all obligations under the contract.
To cancel this transaction, mail or deliver a signed and dated copy of this 
cancellation notice, or any other written notice, or mail to:
WNH Construction Inc.
20018 Knollwood Dr, Saratoga, CA. 95070
Not later than 3 business days from the date of the invoice.
___________________ __________________________________
(Name of Seller) (Project address)
I hereby cancel this transaction 

THE NEGOTIATION, AWARD,

4 of 6 pages

WNH Construction Inc.
20018 Knollwood Dr | Saratoga CA 95070 | CSLB# 1031584
510-648-9999 | http://www.earthquakeretrofit.com/~info | WNHconstruction.com

Notes Continued...
CONSTRUCTION, PERFORMANCE, OF ANY ASPECTS OF THIS AGREEMENT, OR BREACH THEREOF, 
SHALL BE SETTLED BY
BINDING PRIVATE ARBITRATION IN ACCORDANCE WITH THE CONSTRUCTION INDUSTRY 
ARBITRATION RULES OF THE
AMERICAN ARBITRATION ASSOCIATION AND JUDGEMENT UPON THE AWARD RENDERED BY THE 
ARBITRATOR(S) MAY BE
ENTERED IN ANY COURT HAVING JURISDICTION THEREOF.
CLAIMS WITHIN THE MONETARY LIMIT OF THE SMALL CLAIMS COURT SHALL BE LITIGATED 
IN SUCH COURT AT THE
REQUEST OF EITHER PARTY, SO LONG AS BOTH PARTIES LIMIT THEIR RIGHT TO RECOVERY 
TO THE JURISDICTION OF THE
SMALL CLAIMS COURT.
ANY CLAIM FILED IN SMALL CLAIMS COURT SHALL NOT BE DEEMED TO BE A WAIVER OF THE 
RIGHT TO ARBITRATE, AND IF
A COUNTER CLAIM IN EXCESS OF THE JURISDICTION OF THE SMALL CLAIMS COURT IS 
FILED IN THE MUNICIPAL OR
SUPERIOR COURT, THEN THE PARTY FILING IN SMALL CLAIMS COURT MAY DEMAND 
ARBITRATION PURSUANT TO THIS
PARAGRAPH.
NOTICE: BY INITIALING IN THE SPACE BELOW YOU ARE AGREEING TO HAVE ANY DISPUTE 
ARISING OUT OF THE MATTERS
INCLUDED IN THE “ARBITRATION OF DISPUTES” PROVISION DECIDED BY NEUTRAL 
PRIVATE ARBITRATION AS PROVIDED
BY CA LAW AND YOU ARE GIVING UP ANY RIGHTS YOU MIGHT POSSESS TO HAVE 
THE DISPUTE LITIGATED IN A
COURT OR JURY TRIAL. BY INITIALING IN THE SPACE BELOW YOU ARE GIVING UP 
JUDICIAL RIGHTS TO DISCOVERY AND
APPEAL, UNLESS THOSE RIGHTS ARE SPECIFICALLY INCLUDED IN THE
“ARBITRATION OF DISPUTES” PROVISION. IF YOU REFUSE TO SUBMIT TO ARBITRATION 
AFTER AGREEING TO THIS
PROVISION, YOU MAY BE COMPELLED TO ARBITRATE UNDER THE AUTHORITY OF THE 
BUSINESS AND PROFESSIONS
CODE OF OTHER APPLICABLE LAWS. YOUR AGREEMENT TO THIS ARBITRATION PROVISION IS 
VOLUNTARY.
WE HAVE READ AND UNDERSTAND THE FOREGOING AND AGREE TO SUBMIT DISPUTES ARISING
OUT OF THE MATTERS INCLUDED IN THE “ARBITRATION OF DISPUTES” PROVISION TO 
NEUTRAL"
"PRIVATE ARBITRATION."
"IN THE EVENT THAT CONTRACTOR AND OWNER HAVE NOT EACH INITIALED THE ARBITRATION 
PROVISION ABOVE, THEN
IT SHALL BE CONCLUSIVELY AGREED WITHOUT A SUBSEQUENT WRITTEN AGREEMENT BY ALL 
PARTIES, THAT NEITHER
PARTY AGREES TO ARBITRATE AND THE ARBITRATION OF DISPUTES PROVISION SHALL NOT 
BE DEEMED TO BE A PART OF
THIS
AGREEMENT."
"THREE DAY RIGHT TO CANCEL
You, the buyer, have the right to cancel this contract within three business 
days. You may cancel by e-mailing, mailing, faxing, or delivering
a written notice to the contractor at the contractor’s place of business by 
midnight of the third business day after you received a signed and
dated copy of the contract that includes this notice. Include your name, your 
address, and the date you received the signed copy of the
contract and this notice. If you cancel, the contractor must return to you 
anything you paid within 10 days of receiving the notice of
cancellation. For your part, you must make available to the contractor at your 
residence, in substantially as good condition as you received
it, any goods delivered to you under this contract or sale. Or, you may, if you 
wish, comply with the contractor’s instructions on how to return
the goods at the contractor’s expense and risk. If you do make the goods 
available to the contractor and the contractor does not pick them
up within 20 days of the date of your notice of cancellation, you may keep them 
without any further obligation. If you fail to make the goods
available to the contractor, or if you agree to return the goods to the 
contractor and fail to do so, then you remain liable for performance of
all obligations under the contract.
The law requires that the contractor give you a notice explaining your right to 
cancel. By approving this quote you agree you have read the
terms and condition and the contractor has given you a ‘Notice of the 
Three-Day Right to Cancel’."
"SEVEN DAY RIGHT TO CANCEL"
This notice is to be provided to the buyer for any contract that is written for 
the repair or restoration of residential premises damaged by any
sudden or catastrophic event for which a state of emergency has been declared 
by the President of the United States or the Governor, or
for which a local emergency has been declared by the executive officer or 
governing body of any city, county, or city and county
You, the buyer, have the right to cancel this contract within seven business 
days. You may cancel by e-mailing, mailing, faxing, or
delivering a written notice to the contractor at the contractor’s place of 
business by midnight of the seventh business day after you received
a
signed and dated copy of the contract that includes this notice.
Include your name, your address and mail to:
"WNH Construction Inc.
20018 Knollwood, Saratoga, Ca. 95070
License #1031584"
If you cancel, the contractor must return to you anything you paid within 10 
days of receiving the notice of cancellation. For your part, you
must make available to the contractor at your residence, in substantially as 
good condition as you received it, any goods delivered to you
under this contract or sale. Or, you may, if you wish, comply with the 
contractor’s instructions on how to return the goods at the contractor’s

5 of 6 pages

WNH Construction Inc.
20018 Knollwood Dr | Saratoga CA 95070 | CSLB# 1031584
510-648-9999 | http://www.earthquakeretrofit.com/~info | WNHconstruction.com

Notes Continued...
expense and risk. If you do make the goods available to the contractor and the 
contractor does not pick them up within 20 days of the date
of your notice of cancellation, you may keep them without any further 
obligation. If you fail to make the goods available to the contractor, or
if you agree to return the goods to the contractor and fail to do so, then you 
remain liable for performance of all obligations under the
contract.
The law requires that the contractor give you a notice explaining your right to 
cancel. If you approve this contact and make a deposit, you
agree the contractor has given you a ‘Notice of the Seven- Day Right to 
Cancel’."
"WARRANTY & DISCLAIMERS"
The Contractor guarantees the work will meet trade standard of good 
workmanship. Contractor warrants that materials of good quality will
be selected. Contractor warranties are limited to the cost of labor and 
materials only and exclude ordinary wear and tear or abuse by others.
All the work performed by Contractor will be covered under the 1-year warranty 
after the completion. All the structural work will have a 10year warranty.
"For Earthquake Seismic Work"
Residential seismic strengthening is designed for seismic risk reduction. In no 
way does it make a house earthquake proof. Due to the
unpredictability of seismic events, no warranty is expressed or implied. WNH 
Construction is not responsible for sub standard plumbing
and electrical, or problems that may arise from, in walls that receive seismic 
components.
"CUSTOMER ACKNOWLEDGMENT
I hereby acknowledge receipt of a fully completed copy of this home improvement 
agreement and all notices listed below:
• Commercial General Liability Insurance
• Workers’ Compensation Insurance Notice
• Performance of Extra or Change-order Work
• Mechanics’ Lien Warning
• Contractors Board Notice
• Notice of Cancellation
• Arbitration of Disputes
• Three/Seven-Day Right to Cancel"
By approving this contract and paying for the deposit. You agree that the 
contractor has given you proper notice for the listed
documentation above.

6 of 6 pages